United States Federal Circuit
ENGLAND v. THE SHERMAN R. SMOOT CORP., 03-1461
The award of compensation to defendant for a delay in the completion of a construction contract is reversed where Armed Services Board of Contract Appeals used the improper rebuttable presumption that plaintiff had caused the delay.
Appellate Information
- Decided 11/03/2004
- Published 11/03/2004
Judges
Court
- United States Federal Circuit