United States Federal Circuit

The Armed Services Board of Contract Appeals correctly held that a government contractor had failed to prove an essential element of its claim for "Eichleay" damages covering its unabsorbed home office overhead costs during a period of government-caused delay in contract performance.

Appellate Information

• Decided 05/05/2003
• Published 05/05/2003

Judges

• FRIEDMAN, Senior Circuit Judge., Before MICHEL, Circuit Judge, FRIEDMAN, Senior Circuit Judge, and LINN, Circuit Judge.

Court

• United States Federal Circuit

Counsel

• For Appellant:
  
• Judith Ward Mattox, of Colorado Springs, CO, argued for appellant.


• For Appellees:
  
• Carolyn J. Craig, Trial Attorney, Commercial Litigation Branch, Civil Division, Department of Justice, of Washington, DC, argued for appellee.   With her on the brief were Robert D. McCallum, Jr., Assistant Attorney General;  David M. Cohen, Director;  and Donald E. Kinner, Assistant Director.   Of counsel on the brief was Major John B. Alumbaugh, Department of the Army, United States Army Legal Services Agency, of Arlington, VA.