United States Eleventh Circuit
ASSOC. MECH. CONTRACTORS, INC. v. MARTIN K. EBY CONSTR. CO., INC., 00-10784
Under a construction subcontract that incorporated notice provisions of prime contract and its own notice provisions for delay damages, prime contractor's actual notice of delay will not excuse subcontractor's failure to provide timely notice.
Appellate Information
- Decided 11/09/2001
- Published 11/09/2001
Judges
- JOHN R. GIBSON, Circuit Judge:, Before EDMONDSON, HILL and GIBSON , Circuit Judges.
Court
- United States Eleventh Circuit
Counsel
- For Appellant:
- Martin R. Salzman,Stephen M. Phillips, Hendrick, Phillips, Schemm & Salzman, Atlanta, GA, for Associated Mechanical Contractors, Inc., George D. Wenick, Smith, Currie & Hancock, LLP, Atlanta, GA, for Martin K. Eby Const. Co., Inc.